GetTenderAI

France – Travaux de construction de bâtiments – Construction de 12 Maisons individuelles en Accession sociale

DeadlineSeptember 10, 2026 at 12:00 PM58 days left

AI summary

This tender concerns the construction of 12 individual houses for social housing in France. The project aims to deliver affordable housing units through a social home-ownership programme administered by La Ruche Habitat.

#construction#residential building#social housing#france#individual houses#accession sociale
Fit for

Construction companies or building contractors with experience in residential projects and social housing development are invited to bid.

Key requirements

Suppliers must be qualified construction contractors with proven experience in residential building projects. They should demonstrate capacity to deliver housing units on schedule and meet social housing construction standards.

Frequently asked questions

  • What is this tender about?

    This tender concerns the construction of 12 individual houses for social housing in France. The project aims to deliver affordable housing units through a social home-ownership programme administered by La Ruche Habitat.

  • What are the requirements for suppliers?

    Suppliers must be qualified construction contractors with proven experience in residential building projects. They should demonstrate capacity to deliver housing units on schedule and meet social housing construction standards.

  • What type of company should bid?

    Construction companies or building contractors with experience in residential projects and social housing development are invited to bid.

  • Who is the buyer?

    The buyer is La Ruche Habitat.

  • When does this tender close?

    Submissions close on September 10, 2026.

Construction de 12 Maisons individuelles en Accession sociale

Buyer
La Ruche Habitat
Buyer ID: 89224·Montagu Alain
22 Place de Juranville, 18000, Bourges
0675643620amontagu@franceloire.frhttps://www.franceloire.fr/
Body responsible for review procedures
Tribunal judiciaire d'Orléans
Buyer ID: FBB34A39-9E9E-DD60-8BE8CC8C691E3FE9
7 Rue des Huguenots, 45044, Orleans
(33)238745834tj-orleans@justice.fr
Other organization
Avenue-Web Systèmes
Buyer ID: FBB349E9-D192-FD57-8D360F7DE77825B6
38170, Seyssinet-Pariset
+33480041260publications-joue@aws-france.com
Other organization
LA RUCHE HABITAT
Buyer ID: FBB34A28-B01D-01B3-4547497EBDA98574
33 Rue du faubourg de Bourgogne, 45000, Orleans
0248480200sguet@laruchehabitat.fr
Other organization
Tribunal judiciaire d'Orléans
Buyer ID: FBB34A50-FDCB-D3CC-A6AC14C7E7C5C621
7 Rue des Huguenots, 45044, Orleans
(33)238745834tj-orleans@justice.fr
Other organization
Tribunal judiciaire d'Orléans
Buyer ID: FBB34A6C-9254-3DDE-E48032A02434E40B
7 Rue des Huguenots, 45044, Orleans
(33)238745834tj-orleans@justice.fr

Computing match…

AI document analysis

We read the tender PDFs and DOCX files and surface key requirements, deadlines, budget and red flags.

Loading…