GetTenderAI

France – Travaux de construction de bâtiments liés à la santé – Marché de travaux de construction de la Pharmacie à Usage Intérieur (PUI) du CHRU de Nancy

DeadlineApril 30, 2026 at 03:00 PMClosed 76 days ago

AI summary

This tender concerns construction works for an in-house pharmacy (PUI) at the regional university hospital centre in Nancy. The project includes a 21-month overall execution timeline covering preparation and construction phases across multiple work packages, with 20 months allocated for the construction works themselves.

#construction#healthcare facility#pharmacy#nancy#france#public works#hospitals
Fit for

Established construction companies with proven experience in healthcare building projects and the financial and technical capacity to deliver complex construction works should submit bids.

Key requirements

Bidders must be qualified construction contractors capable of executing healthcare facility construction works. Compliance with public procurement regulations and ability to meet the 20-month construction deadline are essential.

Frequently asked questions

  • What is this tender about?

    This tender concerns construction works for an in-house pharmacy (PUI) at the regional university hospital centre in Nancy. The project includes a 21-month overall execution timeline covering preparation and construction phases across multiple work packages, with 20 months allocated for the construction works themselves.

  • What are the requirements for suppliers?

    Bidders must be qualified construction contractors capable of executing healthcare facility construction works. Compliance with public procurement regulations and ability to meet the 20-month construction deadline are essential.

  • What type of company should bid?

    Established construction companies with proven experience in healthcare building projects and the financial and technical capacity to deliver complex construction works should submit bids.

  • Who is the buyer?

    The buyer is Centre Hospitalier Régional Universitaire de Nancy.

  • When does this tender close?

    Submissions close on April 30, 2026.

Travaux de construction de la Pharmacie à Usage Intérieur (PUI) du CHRU de Nancy : La durée d'exécution globale de l'ensemble des marchés (comprenant la période de préparation et le délai d'exécution des travaux de chacun des marchés allotis) est de 21 mois à compter de la date fixée par l'OS précisant la date de démarrage de la période de préparation (hors période de GPA). Le délai global d'exécution de l'ensemble des travaux allotis est de 20 mois.

Buyer
Centre Hospitalier Régional Universitaire de Nancy
Buyer ID: 20004216600013·Direction des Achats du GHT Hôpitaux Sud Lorraine
29 avenue du Maréchal de Lattre de Tassigny - CO 60034, 54035, Nancy cedex
+33 3 83 85 10 91i.langbour@chru-nancy.frhttps://www.chu-nancy.fr
Body responsible for review procedures
Tribunal Administratif de Nancy
Buyer ID: 17540005000019·Greffe du Tribunal Administratif de Nancy
5 place de la Carrière - CO 20038, 54036, Nancy cedex
+33 3 83 17 43 43greffe-ta-nancy@juradm.frhttps://nancy.tribunal-administratif.fr

Computing match…

AI document analysis

We read the tender PDFs and DOCX files and surface key requirements, deadlines, budget and red flags.

Loading…