GetTenderAI

France – Travaux de cloisonnement – Marché de travaux de construction de la Pharmacie à Usage Intérieur (PUI) du CHRU de Nancy : Cloisons laboratoires / cloisons frigorifiques

DeadlineSeptember 4, 2026 at 03:00 PMCloses today

AI summary

This tender concerns construction works for the Internal Use Pharmacy (PUI) at Nancy's University Hospital Centre, specifically partitioning work for laboratory partitions and refrigerated partitions. The project spans 21 months total including preparation and execution phases across multiple work packages.

#hospital construction#pharmacy works#partitioning#nancy#france#medical facilities
Fit for

Construction companies and specialized contractors experienced in hospital pharmacy construction and laboratory/refrigerated partition installation should bid.

Key requirements

Suppliers must be qualified construction contractors capable of executing partitioning and specialized laboratory and refrigerated partition installations. They should have experience with hospital pharmacy construction and ability to meet the 20-month execution timeline.

Frequently asked questions

  • What is this tender about?

    This tender concerns construction works for the Internal Use Pharmacy (PUI) at Nancy's University Hospital Centre, specifically partitioning work for laboratory partitions and refrigerated partitions. The project spans 21 months total including preparation and execution phases across multiple work packages.

  • What are the requirements for suppliers?

    Suppliers must be qualified construction contractors capable of executing partitioning and specialized laboratory and refrigerated partition installations. They should have experience with hospital pharmacy construction and ability to meet the 20-month execution timeline.

  • What type of company should bid?

    Construction companies and specialized contractors experienced in hospital pharmacy construction and laboratory/refrigerated partition installation should bid.

  • Who is the buyer?

    The buyer is Centre Hospitalier Régional Universitaire de Nancy.

  • When does this tender close?

    Submissions close on September 4, 2026.

Travaux de construction de la Pharmacie à Usage Intérieur (PUI) du CHRU de Nancy : La durée d'exécution globale de l'ensemble des marchés (comprenant la période de préparation et le délai d'exécution des travaux de chacun des marchés allotis) est de 21 mois à compter de la date fixée par l'OS précisant la date de démarrage de la période de préparation (hors période de GPA). Le délai global d'exécution de l'ensemble des travaux allotis est de 20 mois.

Buyer
Centre Hospitalier Régional Universitaire de Nancy
Buyer ID: 20004216600013·Direction des Achats du GHT Hôpitaux Sud Lorraine
29 avenue du Maréchal de Lattre de Tassigny - CO 60034, 54035, NANCY CEDEX
+33 3 83 85 10 91i.langbour@chru-nancy.frhttps://www.chu-nancy.fr
Body responsible for review procedures
Tribunal Administratif de Nancy
Buyer ID: 17540005000019·Greffe du Tribunal Administratif de Nancy
5 place de la Carrière - CO 20038, 54036, NANCY CEDEX
+33 3 83 17 43 43greffe-ta-nancy@juradm.frhttps://nancy.tribunal-administratif.fr

Computing match…

AI document analysis

We read the tender PDFs and DOCX files and surface key requirements, deadlines, budget and red flags.

Loading…